Early warning notice
See also: NEC early warning notices - a tool of mutual benefit.
The NEC Engineering and Construction Contract 3rd Edition (NEC3) was published in June 2005. It has been adopted as the contract of choice by the government who no longer update the GC Works contracts, and has been endorsed by the ICE whose own suite of contracts will no longer be updated.
The contract makes provision for early warning procedures. Both parties must give early warning of anything that may delay the works, or increase costs as soon as they become aware of them. They should then hold an early warning meeting to discuss how to avoid or mitigate impacts on the project.
If the contractor fails to give early warning of a possible delay to the works, or increase in costs, they will only be compensated for effects that would have remained anyway even if they had given early warning.
If the contractor fails to give early warning of an event that may give rise to a possible delay to the works, or increase in costs, within 8 weeks of becoming aware of the event, they will not be entitled to a change in price, completion date or key date, unless the project manager should have notified the event to the contractor but did not.
They grey area here is whether and when the contractor should have been aware of the event. Judgement is likely to come down to whether and when it would have been reasonable to expect an experienced contractor to be aware of the event.
NB the term 'early warning' can also be used to refer to the identification of a wider hazard such as a climate event. Glossary: Resilience, published by the Department for International Development in 2016, defines an Early Warning System as: ‘The set of capacities needed to generate and disseminate timely and meaningful warning information to enable individuals, communities and organisations threatened by a hazard to prepare and to act appropriately and in sufficient time to reduce the possibility of harm or loss.’
[edit] Related articles on Designing Buildings
- Accepted programme.
- Adversarial behaviour in the UK construction industry.
- Compensation event.
- Delays on construction projects.
- Disallowed cost.
- Duty to warn.
- Extension of time.
- Liquidated damages.
- Loss and expense.
- NEC early warning notices - a tool of mutual benefit.
- NEC3.
- Relevant event.
- Relevant matter.
Featured articles and news
Download your free guide.
Four new types of prior approval for solar developments
Online Planning Portal application types from 5 September.
Election fails to spark construction industry revival
Contract awards and planning; post election.
Making diversity and inclusion easy for SMEs
The CIOB tool for companies with limited resources.
Sustainable Futures: Redefining Retrofit for Net Zero Living
BSRIA Briefing 2024, initial speakers announced.
Looking back at the UK's first Passivhaus leisure centre
Reflections on St Sidwell’s Point with CIAT.
A-Level results and electrical apprenticeships
Electrical Skills Index highlights areas with skills shortages.
One of the world's more unusual drive-throughs.
A quick introduction.
Hadrian's Wall Path and the national trails
The trails are heritage assets in their own right.
Articles on timely advice and hydraulic lime.
Building Designers Association of Australia
CIAT and BDAA sign Memorandum of Understanding.
Built Environment Inclusive partners issue statement committed to inclusion.
Building regulation requirements can have unintended consequences.
CIOB announces 2024/25 vice president
Sustainability champion Professor Saul Humphrey.
Accelerating towards a net-zero built environment.
Comments
[edit] To make a comment about this article, or to suggest changes, click 'Add a comment' above. Separate your comments from any existing comments by inserting a horizontal line.